Warranty, Assurance, and Payment Clause

SHREE BADREE BUILDTECH PVT LTD is committed to delivering high-quality construction services with a strong emphasis on structural integrity and customer satisfaction. This document outlines the scope, coverage, exclusions, claim process for our construction projects, and the payment terms, ensuring clarity and peace of mind for our valued clients.

1. Structural Warranty

1.1 Coverage Period: SHREE BADREE BUILDTECH PVT LTD provides a comprehensive structural warranty for a period of [insert warranty period, e.g., 10 years] from the date of project completion. This warranty covers any defects or failures in the structural components of the building that arise from substandard materials or poor workmanship.

1.2 Covered Components: The structural warranty encompasses the following key elements of the building’s framework:

• Foundations: This includes footings, slabs, and any other foundational elements critical to the building’s stability.
• Load-bearing Walls: Any walls that support the weight of the building and contribute to its structural integrity.
• Beams and Columns: Structural elements that bear loads and provide support throughout the building.
• Roof Structure: The framework supporting the roof, including trusses, rafters, and any other structural components.
• Floor Structure: Includes joists, subflooring, and any other elements that provide support to the floors.

During the warranty period, SHREE BADREE BUILDTECH PVT LTD will repair or replace any defective structural components at no additional cost to the client.

2. Exclusions

2.1 Non-structural Components: The structural warranty specifically excludes all non-structural components and systems. These items are covered by the warranties and guarantees provided by their respective manufacturers and suppliers. Exclusions include:

• Electrical Systems: All electrical installations, such as wiring, switches, sockets, circuit breakers, and other electrical fittings, are not covered under this structural warranty. Clients should refer to the warranties provided by the manufacturers or installers of these components.
• Plumbing Systems: All plumbing installations, including pipes, faucets, sanitary fixtures, and drainage systems, are excluded from this structural warranty. These components are subject to the warranty and guarantee provided by their respective manufacturers and suppliers.
• Finishing Items: All finishing items, including but not limited to flooring, tiling, painting, fixtures, and fittings, are excluded from this structural warranty. These items are covered under the warranty and guarantee provided by their respective manufacturers and suppliers.

3. Third-Party Accessories Warranty

3.1 Manufacturer’s Warranty: All accessories and non-structural components installed during the construction process are covered by the respective warranties and guarantees of their original manufacturers and sellers. This includes:

• Electrical Components and Systems: Clients should contact the manufacturer or installer for any warranty claims or service requests related to electrical components.
• Plumbing Fixtures and Systems: Warranty claims or service requests for plumbing fixtures and systems should be directed to the manufacturer or installer.
• Finishing Items and Decorative Elements: Warranty claims or service requests for finishing items should be directed to the manufacturer or supplier.

SHREE BADREE BUILDTECH PVT LTD is not responsible for any defects, failures, or performance issues related to these components. Clients must address any concerns directly with the original suppliers as per their warranty terms.

4. Limitation of Liability

4.1 Scope of Liability: Our liability under this structural warranty is strictly limited to the repair or replacement of defective structural components within the specified warranty period. SHREE BADREE BUILDTECH PVT LTD shall not be liable for:

• Incidental or Consequential Damages: Any incidental or consequential damages arising from the use of non-structural items not covered by our warranty.
• Improper Use, Negligence, or Alterations: Defects or failures resulting from improper use, negligence, or alterations made by the client or third parties are not covered under this warranty.
• Natural Wear and Tear: Normal wear and tear or damage caused by natural disasters, including but not limited to earthquakes, floods, and hurricanes, are excluded from this warranty.

5. Claim Process

5.1 Notification: To make a claim under this structural warranty, clients must notify SHREE BADREE BUILDTECH PVT LTD in writing within 30 days of discovering a defect. The notification should include:

• A detailed description of the defect.
• Supporting documentation or evidence, such as photographs or inspection reports.
• The date the defect was discovered.

5.2 Inspection and Assessment: Upon receiving a warranty claim, SHREE BADREE BUILDTECH PVT LTD will arrange for an inspection and assessment of the defect by our authorized personnel. Clients must allow reasonable access to the property for this purpose.

5.3 Repair or Replacement: If the defect is covered under this structural warranty, SHREE BADREE BUILDTECH PVT LTD will undertake the necessary repairs or replacement of defective components at no additional cost to the client. The decision to repair or replace will be at the sole discretion of SHREE BADREE BUILDTECH PVT LTD, based on the nature and extent of the defect.

6. Maintenance Responsibilities

6.1 Client Responsibilities: To maintain the validity of this warranty, clients are responsible for the regular maintenance and care of the building. This includes:

• Conducting routine inspections and maintenance of structural components.
• Promptly addressing any issues that may arise to prevent further damage.
• Following the recommended guidelines for the use and maintenance of non-structural components as provided by their manufacturers.

Failure to properly maintain the building may void the warranty.

7. General Conditions

7.1 Entire Agreement: This Warranty and Assurance Clause constitutes the entire agreement between SHREE BADREE BUILDTECH PVT LTD and the client regarding the structural warranty. It supersedes all prior agreements, representations, or understandings, whether written or oral.

7.2 Modifications: Any modifications or amendments to this warranty must be made in writing and signed by an authorized representative of SHREE BADREE BUILDTECH PVT LTD.

7.3 Governing Law: This warranty shall be governed by and construed in accordance with the laws of [insert jurisdiction]. Any disputes arising from or related to this warranty shall be subject to the exclusive jurisdiction of the courts in [insert jurisdiction].

8. Payment Clause

8.1 Payment Terms: All payments for the construction project must be made in accordance with the agreed-upon terms and conditions outlined in the construction agreement. This includes adherence to the payment schedule, amounts, and deadlines specified in the agreement.

8.2 Payment Schedule: The payment schedule typically includes the following milestones:

• Initial Deposit: A percentage of the total project cost is due upon signing the construction agreement.
• Progress Payments: Payments are due at various stages of the project, such as completion of the foundation, framing, roofing, and other major milestones.
• Final Payment: The remaining balance is due upon project completion and final inspection, subject to the client’s approval.

8.3 Taxes and Fees: All applicable taxes, fees, and charges related to the construction project are the responsibility of the client and must be paid in full as per the construction agreement.

8.4 Delayed Payments: In the event of delayed payments, SHREE BADREE BUILDTECH PVT LTD reserves the right to:

• Suspend Work: Suspend all work on the project until payment is received.
• Impose Late Fees: Charge late fees as specified in the construction agreement.
• Terminate Agreement: Terminate the construction agreement if payments are significantly delayed, and retain any payments already made as compensation for work completed and losses incurred.

8.5 Payment Methods: Payments can be made through the following methods:

• Bank transfer
• Cheque
• Any other method agreed upon by both parties

8.6 Payment Confirmation: Clients are required to provide proof of payment, such as bank transfer receipts or cheque copies, to SHREE BADREE BUILDTECH PVT LTD for record-keeping and verification purposes.

8.7 Payment and Warranty Validity: The validity of the warranty and guarantee provided by SHREE BADREE BUILDTECH PVT LTD is contingent upon the client disbursing all payments, applicable taxes, penalties, and any other dues in a timely manner as per the construction agreement. Failure to adhere to the payment schedule, including the settlement of any penalties for late payments, will render the warranty and guarantee null and void.

9. Contact Information

For any claims, inquiries, or further information regarding the structural warranty or payment terms, clients can contact us at:

📞 +(91)-9625803339
📧 deepak@sbbt.in
🌐 www.sbbt.in

10. Our Commitment

SHREE BADREE BUILDTECH PVT LTD is dedicated to building with quality, trust, and excellence. We stand by our work and are committed to ensuring that our clients are satisfied with the strength and durability of their construction projects. Our comprehensive structural warranty and clear payment terms are a testament to our confidence in the quality of our materials and workmanship, providing our clients with peace of mind for years to come.

Shree Badree Build Tech Pvt Ltd.

Build with Quality, Trust, and Excellence